TERMS AND CONDITIONS
Effective Date: 11 Feb 2025
Company Name: Silver Leaf Developments Pty. Ltd.
ABN: 68 440 4040
Contact Email: enquiries@silverleaf.au
Welcome to Silver Leaf Developments Pty. Ltd. (“the Company”, “we”, “us”, or “our”). These Terms and Conditions govern your use of our services, including property development consultations, project management, construction services, and the use of our website (“Website”). By engaging with us or using our Website, you agree to be bound by the following Terms and Conditions. Please read them carefully. If you do not agree to these Terms and Conditions, you must not use our Services or Website.
1. ACCEPTANCE OF TERMS
By engaging Silver Leaf Developments Pty. Ltd. or using our Website, you agree to comply with these Terms and Conditions and any other rules, policies, or guidelines referenced herein.
2. DEFINITIONS
- Client: Refers to the person or entity engaging the Company’s services.
- Project: Any property development, construction, or related work provided by the Company.
- Services: Any services offered by the Company, including consultations, project management, construction, design, etc.
- Website: Refers to the online platform owned and operated by the Company, accessible at silverleaf.au.
3. SERVICES
Silver Leaf Developments Pty. Ltd. offers a variety of property development services, including but not limited to:
- Feasibility studies
- Project management
- Property design and planning
- Construction management
- Renovations and refurbishment
- Marketing and branding for property developments
All services are subject to availability and the specific terms outlined in individual contracts or agreements.
4. USE OF WEBSITE
By accessing or using our Website, you agree to comply with these Terms and Conditions, as well as any applicable laws and regulations. You must not use the Website for any unlawful purposes or in a way that could harm the Company, its customers, or third parties.
5. WEBSITE CONTENT AND INTELLECTUAL PROPERTY
The content on our Website, including text, images, designs, and all other material, is owned by or licensed to Silver Leaf Developments Pty. Ltd. and is protected by intellectual property laws. You may view, download, and print materials from the Website for personal, non-commercial use only. You must not copy, modify, distribute, or exploit any content for commercial purposes without the express written consent of the Company.
6. LINKS TO THIRD-PARTY WEBSITES
Our Website may contain links to third-party websites for your convenience. These websites are not under our control, and we are not responsible for the content, accuracy, or availability of any linked sites. Use of third-party websites is at your own risk, and we recommend you review their terms and conditions and privacy policies.
7. LIMITATION OF LIABILITY (SERVICES)
To the fullest extent permitted by law, Silver Leaf Developments Pty. Ltd., its directors, employees, agents, subcontractors, or affiliates shall not be liable for any loss, damage, or injury of any kind, whether direct, indirect, incidental, special, consequential, or otherwise, including but not limited to:
- Loss of profit, business, or goodwill;
- Delays or disruptions to the Project due to unforeseen circumstances, including but not limited to weather, supply chain disruptions, or third-party delays;
- Defects or damage arising from the use of third-party contractors, suppliers, or materials;
- Any liability arising from changes or alterations made to the property after completion.
The Company will not be liable for any damages arising from the Client’s failure to provide accurate information, adhere to regulatory requirements, or fulfil any Client obligations outlined in the project agreement.
8. LIMITATION OF LIABILITY (WEBSITE USE)
Silver Leaf Developments Pty. Ltd. does not guarantee that the Website will be free from errors, viruses, or other harmful components. You use the Website at your own risk. To the fullest extent permitted by law, we exclude all liability for any loss or damage arising from your use of, or inability to use, our Website.
9. QUOTATIONS AND ESTIMATES
All estimates or quotations provided by Silver Leaf Developments Pty. Ltd. are valid for [30 days] from the date issued. The Company reserves the right to amend or withdraw any quotation prior to acceptance. Once a quotation is accepted, it constitutes a binding agreement for the Services specified, subject to these Terms and Conditions.
10. PAYMENT TERMS
The Client agrees to make payments according to the payment schedule outlined in the contract or agreement for services.
- Deposit: A deposit of [percentage or fixed sum] must be paid upon acceptance of the quotation.
- Progress Payments: Progress payments must be made in accordance with the agreed schedule.
- Final Payment: Final payment must be made upon completion of the Services and/or Project.
Failure to pay on time may result in delays in the delivery of Services or suspension of work. Late payments will attract an interest rate of 20% per annum, calculated daily.
11. CANCELLATION AND TERMINATION
-
Client Cancellation: If the Client wishes to cancel the Services, the Client must provide written notice to the Company. Any deposits or progress payments made are non-refundable, unless otherwise specified in the individual contract.
-
Company Cancellation: Silver Leaf Developments Pty. Ltd. reserves the right to terminate the agreement at its sole discretion if the Client breaches any terms, fails to make payments, or engages in unlawful activity.
In the event of termination, the Client remains liable for any costs incurred up to the termination date.
12. INDEMNITY
The Client agrees to indemnify and hold harmless Silver Leaf Developments Pty. Ltd., its directors, employees, and agents from and against any claims, liabilities, losses, damages, and expenses, including legal fees, arising out of or in connection with:
- The Client’s use or misuse of the Services;
- Any breach of these Terms and Conditions by the Client;
- Any claims by third parties resulting from the Client’s actions or omissions.
13. FORCE MAJEURE
Silver Leaf Developments Pty. Ltd. shall not be held responsible for any delays or failure to perform its obligations under these Terms due to events beyond its reasonable control, including but not limited to acts of God, war, strikes, pandemics, government regulations, or supply chain disruptions.
14. INTELLECTUAL PROPERTY (SERVICES)
All intellectual property rights, including but not limited to plans, designs, drawings, reports, and marketing materials created by Silver Leaf Developments Pty. Ltd. in the course of providing Services, shall remain the property of the Company unless expressly agreed otherwise in writing.
The Client is granted a limited, non-exclusive licence to use any materials provided for the purpose of the specific Project.
15. NO WARRANTY
Silver Leaf Developments Pty. Ltd. makes no warranties, whether express or implied, regarding the Services, Website, or any materials provided, including but not limited to any implied warranties of merchantability or fitness for a particular purpose. All Services are provided “as is.”
16. COMPLIANCE WITH LAWS AND REGULATIONS
The Client is responsible for ensuring compliance with all applicable local, state, and federal laws and regulations in connection with the Project. Silver Leaf Developments Pty. Ltd. will not be held responsible for any violations arising from the Client’s failure to adhere to legal requirements.
17. PRIVACY POLICY
Your use of the Website is also governed by our Privacy Policy, which explains how we collect, use, and protect your personal information. By using our Website, you consent to the collection and use of information as outlined in the Privacy Policy.
18. DISPUTE RESOLUTION
Any disputes arising from these Terms and Conditions shall first be attempted to be resolved through good-faith negotiations between the parties. If unresolved, the dispute may be referred to mediation in Queensland under the rules of the relevant mediation authority. If mediation is unsuccessful, either party may seek legal recourse through the courts of Queensland.
19. AMENDMENTS
Silver Leaf Developments Pty. Ltd. reserves the right to amend these Terms and Conditions at any time. Any changes will be communicated to the Client, and continued engagement with the Company’s Services or use of the Website will be considered acceptance of the updated terms.
20. SEVERABILITY
If any provision of these Terms and Conditions is found to be invalid or unenforceable, the remaining provisions shall continue in full force and effect.
21. GOVERNING LAW
These Terms and Conditions are governed by and construed in accordance with the laws of Queensland, Australia. The Client agrees to submit to the exclusive jurisdiction of the courts of Queensland for the resolution of any disputes.
By engaging Silver Leaf Developments Pty. Ltd. or using our Website, you acknowledge that you have read, understood, and agreed to these Terms and Conditions.
Contact Us:
For any questions or concerns about these Terms and Conditions, please contact us at:
Silver Leaf Developments Pty. Ltd.
enquiries@silverleaf.au.